---

18 C.F.R. § 1308.24   Undue delay in Contracting Officer's decision.

Title 18 - Conservation of Power and Water Resources

Title 18: Conservation of Power and Water Resources
PART 1308—CONTRACT DISPUTES
Subpart C—Board of Contract Appeals

Browse Previous |  Browse Next

§ 1308.24   Undue delay in Contracting Officer's decision.

(a) If there is an undue delay by a Contracting Officer in issuing a decision on a claim, the Contractor may request the Chairman to direct the Contracting Officer to issue a decision within a specified period of time.

(b) A request under this section shall:

(1) Be in writing;

(2) State the date on which the claim was submitted to the Contracting Officer.

(3) State the date suggested for issuance of a decision by the Contracting Officer.

(c) TVA may reply to a motion under this section within 5 days after its receipt.

(d) The Chairman shall issue a written decision on the request. If granted, the decision shall specify the date by which the Contracting Officer's decision is to be rendered, and a copy shall be served on the Contracting Officer.

Browse Previous |  Browse Next