43 C.F.R. PART 5470—CONTRACT MODIFICATION—EXTENSION—ASSIGNMENT
Title 43 - Public Lands: Interior
Authority: 30 U.S.C. 601; 43 U.S.C. 1181e and 1740.
Source: 35 FR 9787, June 13, 1970, unless otherwise noted.
In order to be considered, written requests for extension shall be delivered to the appropriate BLM office prior to the expiration of the time for cutting and removal. [57 FR 37477, Aug. 19, 1992] (a) If the purchaser shows that his delay in cutting or removal was due to causes beyond his control and without his fault or negligence, the contracting officer may grant an extension of time, upon written request by the purchaser. Such extension will not exceed one year, and will require an appraisal, if the delay was not imposed by the United States or any State government agency as provided by paragraph (c) of this section. Market fluctuations are not cause for consideration of contract extensions. Additional extensions may be granted upon written request by the purchaser. (b) Notwithstanding the provisions of paragraph (a) of this section requiring reappraisal if the delay was not imposed by the United States or any State government under paragraph (c) of this section, the contracting officer may grant an extension of time, without reappraisal, not to exceed enough time to provide 30 days of operating time, if the delay was due to causes beyond the purchaser's control and without his fault or negligence. No additional extensions may be granted without reappraisal under the provisions of this paragraph. (c) On a showing that the purchaser performed as the average prudent operator would be expected to perform in a like time period prior to any delaying event listed in this paragraph, the contracting officer may grant, without reappraisal, an extension of time not to exceed that necessary to provide an additional amount of operating time equal to operating time lost as a result of: (1) Additional contract requirements incorporated in contract modifications requested by the Government; (2) Delays necessitated by the requirements for consultation with the U.S. Fish and Wildlife Service under the Endangered Species Act; (3) Reviews for cultural resource values; (4) Court injunctions obtained by parties outside the contract; or (5) Closure of operations by State fire protection agencies due to fire danger. (d) Upon written request of the purchaser, the State Director may extend a contract to harvest green timber to allow that purchaser to harvest as salvage from Federal lands timber that has been damaged by fire or other natural or man-made disaster. The duration of the extension shall not exceed the time necessary to meet the salvage objectives. The State Director may also waive reappraisal for such extension. [57 FR 37477, Aug. 19, 1992, as amended at 57 FR 62235, Dec. 30, 1992] (a) If an extension is granted under §5473.4(a), reappraisal by the contracting officer of the material sold will be in accordance with this section. (b) For a cruise sale the timber sold remaining on the contract area shall be reappraised for the purpose of computing the reappraised total purchase price. The reappraised total purchase price shall not be less than the total purchase price established by the contract or last extension. The authorized officer may require that the reappraised total purchase price shall be paid in advance as a condition of granting an extension. (c) For a scale sale each species of timber remaining on the contract area shall be reappraised. The reappraised unit price for each species shall be effective for the remaining life of the contract: Provided, however, The reappraised unit price for each species shall not be less than the unit price established by the contract or previous extension. [52 FR 42587, Nov. 5, 1987 and 53 FR 31002, Aug. 17, 1988, as amended at 56 FR 33833, July 23, 1991; 57 FR 37477, Aug. 19, 1992] (a) The purchaser may not assign the contract or any interest therein without the written approval of the authorized officer. An assignment shall contain all the terms and conditions agreed upon by the parties thereto. (b) The authorized officer will not approve any proposed assignment involving contract performance unless the assignee (1) is authorized to transact business in the State in which the timber or other vegetative resource is located; (2) submits such information as is necessary to assure the authorized officer of his ability to fulfill the contract; and (3) furnishes a performance bond as required by subpart 5451 of this chapter or obtains a commitment from the previous surety to be bound by the assignment when approved. Upon approval of an assignment by the authorized officer, the assignee shall be entitled to all the rights and subject to all the obligations under the contract, and the assignor shall be released from any further liability under the contract.
Title 43: Public Lands: Interior
PART 5470—CONTRACT MODIFICATION—EXTENSION—ASSIGNMENT
Section Contents
§ 5473.1 Application.
§ 5473.4 Approval of request.
§ 5473.4-1 Reappraisal.
§ 5474.1 Conditions; general.
Subpart 5473—Extension of Time for Cutting and Removal
top
§ 5473.1 Application.
top
§ 5473.4 Approval of request.
top
§ 5473.4-1 Reappraisal.
top
Subpart 5474—Contract Assignment
top
§ 5474.1 Conditions; general.
top
